logo

800.626.0054

 
  GlassRatner X Logo    
  • Home
  • About GlassRatner
    • Overview
    • News and Press Releases
    • Case Studies
    • GlassRatner Articles
    • Employment Opportunities
  • Expert Services
    • Construction Claims & Disputes
      • Construction Delay Claims
      • Labor Productivity Claims
      • Design and Construction Defect Claims
      • Force Majeure Claims
      • Acceleration Claims
      • Suspension and Termination Claims
      • Differing Site Conditions Claims
      • Change Claims
    • Construction Defects
    • CPM Schedule Analysis
      • Windows Analysis or Contemporaneous Period Analysis
      • Time Impact Analysis (TIA)
      • Collapsed As-Built
      • Impacted As-Planned
      • As-Planned vs. As-Built
    • Construction Management
      • Contract Administration
      • Implementation of Project Controls
      • Execution of Processes and Procedures
      • Change Management
      • Risk Management
    • Litigation & Arbitration
      • Prudence Evaluation Experts
      • International Arbitration Construction Experts
      • Labor Productivity Analysis Experts
      • Schedule Delay Experts
      • Damage Quantification Experts
      • Design & Construction Defects Experts
      • Acceleration Experts
      • Suspension & Termination Experts
      • Force Majeure Experts
      • Differing Site Conditions Experts
      • Construction Change Experts
      • Standard of Care
    • Project Advisory
      • Construction Readiness Assessment
      • Contracting Strategy Development
      • Cost Risk Assessment
      • Project Audit
      • Project Execution Planning
      • Project Framing
  • Industries Served
    • Buildings & Facilities
      • Buildings
        • Education
        • Government Buildings
        • Commercial Buildings
        • Retail
      • Healthcare
      • Entertainment, Sports & Convention Centers
      • Industrial & Manufacturing
      • Multifamily Housing & Hotels
        • Multifamily Housing
        • Hotels
    • Transportation & Infrastructure
      • Airports
      • Heavy Civil
      • Roads, Highways, Bridges & Rail
      • Utilities
      • Water & Wastewater Treatment
    • Oil & Gas Pipelines
      • Land Pipelines
      • Subsea Pipelines
    • Marine & Offshore Production
      • Offshore
      • Ports, Piers & Wharfs
      • Shipbuilding & Vessels
    • Power & Energy
    • Chemical & Petrochemical
    • LNG & NGL
    • Oil & Gas Processing
    • Refining
    • Megaprojects
  • GlassRatner Experts
    • Sam Barakat, PE, Esq., PSP
    • Jacob P. Hammond, CST
    • Lisa Sumner Heard
    • Dennis R. Jasinski, Fellow – ICCP
    • Mohamed W. Khazragui
    • Angela E. Lopez
    • Karen P. Matthews
    • Nicholas V. Ninan, CCP
    • Gabriel Paglicawan
    • Tapan Patni
    • Christopher J. Sullivan
    • Philip D. Barnard, PE
    • David Frinsco
    • Michael T. Gunter, PE, EVP
    • Chad P. Kirlin, PE, PMP
    • Greg Lamberson
    • Pete D. Luan, PMP
    • Charles W. Miller
    • Carolyn L. Morgan, CPA
    • Sean P. Pellegrino, PE
    • Leslie Rucker, CSP
    • Rodney Crawford, CPA
    • Kip Hamilton, CPA, CFE
    • Joel Murovitz, LEED AP
  • Contact Us
  • Client Login
  • Home
  • About GlassRatner
    • Overview
    • News and Press Releases
    • Case Studies
    • GlassRatner Articles
    • Employment Opportunities
  • Expert Services
    • Construction Claims & Disputes
      • Construction Delay Claims
      • Labor Productivity Claims
      • Design and Construction Defect Claims
      • Force Majeure Claims
      • Acceleration Claims
      • Suspension and Termination Claims
      • Differing Site Conditions Claims
      • Change Claims
    • Construction Defects
    • CPM Schedule Analysis
      • Windows Analysis or Contemporaneous Period Analysis
      • Time Impact Analysis (TIA)
      • Collapsed As-Built
      • Impacted As-Planned
      • As-Planned vs. As-Built
    • Construction Management
      • Contract Administration
      • Implementation of Project Controls
      • Execution of Processes and Procedures
      • Change Management
      • Risk Management
    • Litigation & Arbitration
      • Prudence Evaluation Experts
      • International Arbitration Construction Experts
      • Labor Productivity Analysis Experts
      • Schedule Delay Experts
      • Damage Quantification Experts
      • Design & Construction Defects Experts
      • Acceleration Experts
      • Suspension & Termination Experts
      • Force Majeure Experts
      • Differing Site Conditions Experts
      • Construction Change Experts
      • Standard of Care
    • Project Advisory
      • Construction Readiness Assessment
      • Contracting Strategy Development
      • Cost Risk Assessment
      • Project Audit
      • Project Execution Planning
      • Project Framing
  • Industries Served
    • Buildings & Facilities
      • Buildings
        • Education
        • Government Buildings
        • Commercial Buildings
        • Retail
      • Healthcare
      • Entertainment, Sports & Convention Centers
      • Industrial & Manufacturing
      • Multifamily Housing & Hotels
        • Multifamily Housing
        • Hotels
    • Transportation & Infrastructure
      • Airports
      • Heavy Civil
      • Roads, Highways, Bridges & Rail
      • Utilities
      • Water & Wastewater Treatment
    • Oil & Gas Pipelines
      • Land Pipelines
      • Subsea Pipelines
    • Marine & Offshore Production
      • Offshore
      • Ports, Piers & Wharfs
      • Shipbuilding & Vessels
    • Power & Energy
    • Chemical & Petrochemical
    • LNG & NGL
    • Oil & Gas Processing
    • Refining
    • Megaprojects
  • GlassRatner Experts
    • Sam Barakat, PE, Esq., PSP
    • Jacob P. Hammond, CST
    • Lisa Sumner Heard
    • Dennis R. Jasinski, Fellow – ICCP
    • Mohamed W. Khazragui
    • Angela E. Lopez
    • Karen P. Matthews
    • Nicholas V. Ninan, CCP
    • Gabriel Paglicawan
    • Tapan Patni
    • Christopher J. Sullivan
    • Philip D. Barnard, PE
    • David Frinsco
    • Michael T. Gunter, PE, EVP
    • Chad P. Kirlin, PE, PMP
    • Greg Lamberson
    • Pete D. Luan, PMP
    • Charles W. Miller
    • Carolyn L. Morgan, CPA
    • Sean P. Pellegrino, PE
    • Leslie Rucker, CSP
    • Rodney Crawford, CPA
    • Kip Hamilton, CPA, CFE
    • Joel Murovitz, LEED AP
  • Contact Us
  • Client Login

No Harm – No Foul: An Equitable View on Liquidated Damages for Delay

by Bennett Coleman
Construction ClaimsJuly 30, 20070 comments

Liquidated damages (hereafter LDs) for delay can be an emotional topic for owners and contractors, as LDs come into play when the project is delayed and not progressing according to the parties’ expectations. LDs signal a troubled project, often leading to rising tensions which unfortunately divert attention and energy away from completing the project as expeditiously and economically as possible.

What are LDs for Delay?

LDs are commonly defined as when a contractor agrees to pay an Owner a fixed sum, either expressed as a percentage of the contract price or a fixed amount per day of delay in completing agreed upon milestones or project completion dates. The term liquidated implies that the parties have expressly stipulated in the contract the damage amount to be recovered in the event of a delay, regardless of the actual damages incurred by the owner for the delay.

LDs are a benefit to the Owner in that they provide a strong incentive for the contractor to complete its work in a timely manner. The purpose of liquidating or stipulating the damages is to fix the amount to be paid in the event of delay, thereby avoiding the need for the Owner to prove with certainty its actual costs incurred due to delay. Most construction contracts indicate that the liquidated amount to be paid should not be construed as a penalty, but as a good faith estimate of the actual damages that will probably ensue from the delay. LDs are typically meant to cover the Owner’s costs for extended project management/oversight costs, the value of the loss of use of the facility, or the increased finance costs incurred by the Owner as a result of the contractor-caused delay.

What LDs are Not

LDs are not intended to be a revenue stream to the Owner for recovering project cost overruns and should not be intended to recover money from a contractor unless that contractor contributes to the project’s delay by its actions or inactions. Additionally, LDs are not intended to be a penalty for the failure to complete on time, but rather a reasonable approximation of the damages the Owner estimates it will incur due to contractor-caused delays.

The LD Dilemma

Today’s construction projects are larger, more complex, and often riskier than projects completed years ago. Larger and more complex construction projects often require the Owner to place multiple prime contracts. Furthermore, multiple prime contracts often involve extensive interface and coordination issues between various EPC contractors that the Owner is typically required to manage. Multiple prime contracts can lead to an overall delay in completing the entire project if the Owner does not properly manage the project.

However, what happens when a contractor is late in completing a project, which would ordinarily result in it paying LDs, but the Owner has caused a concurrent delay elsewhere that delays it from obtaining beneficial use of the facility? Is the Owner still entitled to collect LDs from the contractor if the Owner could not have started the facility in any event, regardless of the contractor’s delay?

A Case Study of LDs for Delay

Assume the Owner wishes to construct a natural gas fired power plant and has decided to place two parallel prime contracts. The power plant contractor is responsible for building the combined cycle power plant, while the pipeline contractor is responsible for installing the natural gas pipeline that will supply gas to the project. What happens if the pipeline contractor is nine (9) months late in completing the natural gas pipeline, through no fault of the power plant contractor? At the same time, as depicted in the following graphic, the power plant contractor was one (1) month late in completing the power plant but the plant sat idle for 8 months waiting for the pipeline contractor to complete the pipeline to supply the gas necessary to start up the power plant. Is the Owner entitled to recover LDs from the power plant contractor for the one (1) month of delay?

Many construction contracts would allow the Owner to assess the power plant contractor with one (1) month of LDs, as the power plant contractor was indeed late through no fault of the Owner or the pipeline contractor. Does this seem fair considering that the Owner could not have started the power plant due to the pipeline contractor’s delay? In other words, the Owner would have still incurred delay damages due to the pipeline contractor’s delay, even if the power plant contractor had completed on time.

An Equitable Argument – No Harm No Foul

An equity argument can be made in this case study that the Owner could not have started the plant even if the power plant contractor had completed on time due to a lack of natural gas resulting from the pipeline contractor’s delay. Therefore, in this case study, an equity argument can be made that the Owner may not be entitled to recover damages from the power plant contractor because, through no fault of the power plant contractor, the Owner would not have been able to start the facility and sell electricity. Using this argument, there is no reason to penalize the power plant contractor. The Owner would regardless have suffered delay damages due to the pipeline contractor.

This article is not intended to encourage the parties to a contract to disregard any contracts currently in force, but to stimulate debate in the construction law arena for a more equitable view of LDs for delay. A more equitable position could be for the parties to agree in the contract language that LDs for delay should only be assessed if the prime reason a project is delayed is due to the acts or omissions of the contractor. To this end, the parties may wish to include language in the contract similar to the following:

“Notwithstanding anything to the contrary elsewhere in the contract or in law, the Owner and Contractor agree that no liquidated damages for delay shall become due and payable by Contractor to Owner unless the Owner could have completed the facility and started receiving beneficial use of said facility but for Contractor’s delay.”

This no harm – no foul philosophy is similar to the theory of concurrent delay, which is recognized by the courts. In concurrent delay, performance is delayed by causes attributed to both the Contractor and the Owner, thus neither party can recover compensation for the delay.

Conclusions

LDs for delay are an effective means to motivate a contractor to complete a project on time. However, when project conditions deteriorate and tensions rise, the parties are less likely to act in a fair and balanced manner when assessing delays and the resulting LDs for delay. Agreeing up front with the no harm – no foul concept will allow the parties to focus on completing a troubled project without the distracting debates over damages, yet will still allow the Owner to recover LDs for delay when justified.

Source: Christopher J. Sullivan

Released: July 30th, 2007 11:00 AM

Phone: (713) 626-2525

Fax: (713)626-2555

Email: cj********@******************ng.com

Category: construction claims analysis

Subcategory: interface

View Full Article »
Constructive AccelerationPrev
Constructive ChangeNext

Categories

CONTACT US

To find out how our Construction Consultants and Experts can assist you, or for other inquiries, please call 800.626.0054 or

EMAIL US NOW

The views expressed in this article are those of the author(s) and not necessarily the views of GlassRatner, its management, or its other professionals.

logo

GlassRatner (Formerly Interface Consulting) provides a portfolio of professional support services to a wide range of clients including owners, contractors, attorneys, engineers, insurers, and suppliers involved in the engineering and construction process.

Quick Links

  • About GlassRatner
  • Industries Served
  • News & Press Releases
  • GlassRatner Articles
  • GlassRatner Experts
  • Employment Opportunities
  • Client Login

Expert Services

  • Construction Claims & Disputes
  • Construction Defects
  • Construction Management
  • CPM Schedule Analysis
  • Litigation & Arbitration
  • Project Advisory

Corporate Office

  • GlassRatner
  • 5847 San Felipe Street, Suite 1910
  • Houston, TX 77057
  • co*****@******************ng.com
  • 800.626.0054(Phone)
  • 713.626.2555 (Fax)
  • Get Directions
  • Branch Offices
  • Naples, Florida
       
  • GlassRatner
  • Terms of Use
  • Privacy Statement
  • Site built with Port City Media.